House of Lords
|Session 2007 - 08|
Publications on the Internet
PDF Print Version
|Judgments - Reinwood Limited (Respondents) v L Brown & Sons Limited (Appellants)
HOUSE OF LORDS
 UKHL 12
on appeal from:  EWCA Civ 601
OF THE LORDS OF APPEAL
FOR JUDGMENT IN THE CAUSE
Reinwood Limited (Respondents) v L Brown & Sons Limited (Appellants)
Lord Hope of Craighead
Lord Scott of Foscote
Lord Walker of Gestingthorpe
Lord Brown of Eaton-under-Heywood
Lord Neuberger of Abbotsbury
John Marrin QC
(Instructed by Hammonds)
Stephen Furst QC
(Instructed by Hill Dickinson)
17 JANUARY 2008
WEDNESDAY 20 FEBRUARY 2008
HOUSE OF LORDS
OPINIONS OF THE LORDS OF APPEAL FOR JUDGMENT
IN THE CAUSE
Reinwood Limited (Respondents) v L Brown & Sons Limited (Appellants)
 UKHL 12
LORD HOPE OF CRAIGHEAD
1. I have had the advantage of reading in draft the opinion of my noble and learned friend Lord Neuberger of Abbotsbury. I adopt with gratitude his account of the facts and of the provisions of the contract that have given rise to the dispute. I add these brief comments to explain why, after some initial hesitation, I agree with him that the appeal should be dismissed.
2. For the reasons that were explained in Melville Dundas Ltd v George Wimpey UK Ltd  UKHL18,  1 WLR 1136, the background to the case is to be found in the provisions of the Housing Grants, Construction and Regeneration Act 1996. Section 108(1) of that Act provides that a party to a construction contract has the right to refer a dispute arising under the contract to adjudication under a procedure complying with that section. Section 109 provides that a party to a construction contract is entitled to payment by instalments for any work under the contract and that the parties are free to agree the amounts of the payments and the intervals at which, or circumstances in which, they become due. Section 110(1)(a) provides that every construction contract shall provide an adequate mechanism for determining what payments become due under the contract. Section 110(2) provides that every construction contract shall provide for the giving of notice specifying the amount (if any) of the payment made or proposed to be made, and the basis on which that amount was calculated.
3. The provision of the Act that lies at the heart of this case is section 111. It is designed to reduce the incidence of set-off abuse by formalising the process by which the payer claims to be entitled to pay less than that expected by the payee. The mechanism that has been designed for this purpose is, as in the case of section 110(2), the giving of notices. Section 111(1) provides:
A party to a construction contract may not withhold payment after the final date for payment of a sum due under the contract unless he has given an effective notice of intention to withhold payment.
4. It is important to notice the word effective in the passage which I have just quoted. Section 111(2) provides:
To be effective such a notice must specify -
(a) the amount to be withheld and the ground for withholding payment, or
(b) if there is more than one ground, each ground and the amount attributable to it,
and must be given not later than the prescribed period before the final date for payment.
The giving of such a notice will enable a payee who considers that the proposal to withhold is not in accordance with the contract, if he is so minded, to refer the dispute to adjudication under the procedure that section 108 describes. As Lord Hoffmann said in Melville Dundas Ltd v George Wimpey UK Ltd, para 19, the purpose of the notice requirement is to enable the contractor to know immediately and with clarity why a payment is being withheld. The meaning which is conveyed by the word effective is that, if the contractor does not refer the question to adjudication, the employer will not be in default if the amount of which he has given notice is withheld from the amount stated as due in an interim certificate.
5. The standard form of contract which the parties to this case entered into contains provisions which were designed to satisfy the requirements of the statute. The mechanism which is provided for by section 111 is to be found in clause 24, which is headed Damages for non-completion". If the contractor fails to complete the works by the completion date the architect is to issue a certificate to that effect: clause 24.1. This is the trigger for the serving of a notice under clause 24.2 of the kind that section 111 envisages. The mechanism that it provides proceeds in two stages. First, the employer must give notice in writing that he may require payment of, or withhold or deduct, liquidated and ascertained damages: clause 24.2.1. Then, not later than 5 days before the final date for payment of the debt due under the final certificate, the employer may require payment of the liquidated and ascertained damages, which he may then recover as a debt. Or, as happened in this case, he must give a notice under clause 184.108.40.206 that he will deduct liquidated and ascertained damages from monies due to the contractor under an interim certificate. Clause 220.127.116.11 provides that such a notice must specify any amount proposed to be withheld and the ground or grounds for such withholding.
6. On 14 December 2005 the employer received a certificate of non-completion from the architect under clause 24.1 which entitled him to recover an amount of liquidated and ascertained damages. He served the requisite notices on the contractor on 17 January 2006. On 20 January 2006, in reliance upon those notices, he paid to the contractor the sum due under the interim certificate that was then due for payment under deduction of an amount of liquidated and ascertained damages calculated in accordance with the architects certificate of non-completion. The notices which he served, taken together, satisfied all the requirements of an effective notice within the meaning of section 111(1) of the 1996 Act.
7. The contractor claims that the employer was nevertheless in default within the meaning of clause 28.2.1. This is because on 23 January 2006, three days after the employer had paid the amount stated as due in the interim certificate under deduction of an amount calculated in accordance with the architects clause 24.1 certificate of 14 December 2005, the architect granted an extension of time which reduced the amount of the liquidated and ascertained damages to which the employer was entitled under the contract. The question is whether the employer was in default because he did not pay the balance of the amount due to the contractor before the final date for payment under clause 18.104.22.168. In the Court of Appeal Dyson LJ, with whom Mummery and Arden LJJ agreed, answered this question in the negative. He said that a valid clause 22.214.171.124 notice does not cease to be effective when a certificate of non-completion is cancelled:  EWCA Civ 601, para 25. The short question on this appeal is whether this is a sound interpretation of the provisions of this contract.
8. Clause 24.1 provides that, in the event of a new completion date being fixed after the issue of a certificate of non-completion under that sub-clause, such fixing shall cancel that certificate. Nowhere in clause 24, however, is it stated that such fixing will have the effect of cancelling any notices that the employer may have served on the contractor in reliance upon the certificate that is cancelled. Clause 24.2.3 is an important indication to the contrary. Picking up the word effective in section 111(1) of the 1996 Act, it provides:
Notwithstanding the issue of any further certificate of the architect under clause 24.1 any requirement of the employer which has previously been stated in writing in accordance with clause 24.2.1 shall remain effective unless withdrawn by the employer.
The clause is silent on the question as to what is to happen if the further certificate is issued before the requirement is acted upon. I would give the phrase shall remain effective its ordinary meaning in this context. The requirement remains effective whether or not it has been acted upon because there is no indication in the clause to the contrary.
9. The facts of this case do not match those which are envisaged by clause 24.2.3. Clause 24.1 provides that in the event of a new completion date being fixed the architect shall issue such further certificate under clause 24.1 as may be necessary. But no such further certificate was issued by the architect until after the final date for payment of the amount stated as due on the interim certificate. The absence of a clause which deprives the clause 24.2.1 notices of effect in the event of a new completion date being fixed is more directly relevant. But the way clause 24.2.3 deals with the situation that it refers to also supports the employers argument that his notices remained effective despite the cancellation of the original clause 24.1 certificate.
10. Some further support can be drawn from the provisions of clause 24.2.2. It provides for the payment or repayment of any amounts recovered, allowed or paid under clause 24.2.1 if the architect fixes a later completion date. It does not address the point that has arisen in this case directly. But it would be odd, in the light of what clause 24.2.3 provides, for there to be no provision depriving the clause 24.2.1 notices of effect before they had been acted on if it was the intention that they should indeed cease then to be effective in those circumstances. A balance appears to have been struck between setting up a system that gives sufficient notice to the contractor of the amount of the payment proposed to be made and one which, by providing for every possible event, is over-elaborate.
11. In my opinion the conditions of contract ought to be construed in the light of the provisions of the statute that they were intended to give effect to. The concept which is to be found in section 111(1) is that of an effective notice - that is to say of a notice on which the employer is entitled to rely when the time comes for him to act on it unless the question as to the amount which he proposes to withhold is referred to adjudication. A contractor who, on being told that a new completion date has been fixed which reduces his liability in liquidated and ascertained damages, does not refer the matter to adjudication before the final date for payment of the amount due on an interim certificate cannot be heard to say that the employer who withholds the amount of which he has given notice is in default within the meaning of clause 28.2.1.
12. I agree with Dyson LJ that the scheme which emerges from this construction of the contract is a sensible one: para 29. The employer, in such a situation, is entitled to deduct the liquidated and ascertained damages specified in his notice under clause 126.96.36.199 from the amount that is stated to be due in the interim certificate. But he is obliged by clause 24.2.2. to pay or repay any liquidated and ascertained damages that were recovered, allowed or paid under clause 24.2.1 after he has been informed by the architect of the fixing of the new completion date. This must be done within a reasonable time after receipt of that information. The time allowed will be short, having regard to the default provisions in the Scheme for Construction Contracts (England and Wales) Regulations 1998 (SI 1998/649). In this case the employer paid the balance of the amount due on the interim certificate, with interest, on 1 February 2006. It would have been open to him, to avoid having to pay that amount with interest later, to reduce the amount of the deduction notwithstanding the terms of the notice that he had given under clause 188.8.131.52. But he was not in default within the meaning of clause 28.2.1 because he chose not to do so.
LORD SCOTT OF FOSCOTE
13. Having had the advantage of reading in advance the opinion prepared by my noble and learned friend Lord Neuberger of Abbotsbury, I agree that for the reasons he gives this appeal should be dismissed.
LORD WALKER OF GESTINGTHORPE
14. I am in full agreement with the opinion of my noble and learned friend Lord Neuberger of Abbotsbury, which I have had the advantage of reading in draft. I add a few comments of my own, mainly as regards Part II of the Housing Grants, Construction and Regeneration Act 1996 (the 1996 Act). None of my comments detracts from my full agreement with Lord Neubergers opinion.
15. Part II of the 1996 Act was intended to reduce the amount of time, money and other resources wasted on disputes about building contracts (see generally Chapter Nine, Dispute Resolution, in Sir Michael Lathams final report, Constructing the Team, HMSO 1994). In particular, it sought to avoid what my noble and learned friend Lord Hope of Craighead, in Melville Dundas Ltd v George Wimpey UK Ltd  1 WLR 1136, para 42, referred to as set-off abuse by deductions from stage payments, a course of action which can sometimes put unfair pressure on a contractor who is already having liquidity problems.
16. The 1996 Act sought to achieve these aims by two means: by ensuring that building contracts include some basic provisions about stage payments and deductions from stage payments; and by machinery for rapid adjudication, on a provisional basis, of disputes, including (but not limited to) disputes about deductions from stage payments. The first of these objectives is achieved by sections 109 (entitlement to stage payments), 110 (dates for payment) and 111 (notice of intention to withhold payment) together with the default provisions in the Scheme for Construction Contracts (England and Wales) Regulations 1998, SI 1998 No. 649. Within limits permitted by sections 109 to 111 the parties to a written building contract are free to agree the content of the basic provisions which must be included in the contract; but so far as they omit to do so, the Scheme fills the gap.
17. Part II of the 1996 Act, and the Scheme, are therefore most actively engaged in the (probably relatively unusual) case of a written building contract which (while not excepted from the operation of sections 109 to 111) makes no provision whatsoever for stage payments or notices in connection with such payments. A rudimentary contract of that sort will contain no provision for architects interim certificates (indeed, there may be no architect involved at all) and in such a case section 110 performs a useful function in requiring a notice spelling out the employers understanding of the effect of the default provisions in para 2 of Part II of the Scheme, and the amount of the stage payment which the employer considers to be due under those provisions. That lets the parties know where they stand, and serves a useful purpose even when there is no question of a sum being withheld (either as liquidated damages for delay, or for any other reason). In such circumstances the section 110 notice is the nearest equivalent (but is obviously not a close equivalent) to an architects interim certificate.
18. In the more usual case where a standard form of contract is used (such as the JCT standard form used in this case) the requirements of sections 109 to 111 are reproduced in detail in the form of contract and reference to the Scheme is unnecessary (except, as Lord Neuberger points out, in connection with the date for a balancing payment under clause 24.2.2). The notice required by section 110(2) does little more than repeat what the parties already know from the most recent architects interim certificate, unless the employer is proposing to make a deduction (in which case section 111 comes into play). Parliament has recognised this overlap by providing that a section 110(2) notice may suffice as a section 111 notice, so long as it complies with the requirements of section 111(2).
19. All these provisions are, as I have said, aimed at letting the parties know where they stand, in order to avoid unpleasant last-minute surprises and disputes. Parties cannot know where they stand if their obligations are liable to be changed at the last moment, with retrospective effect.
20. Under the JCT form of contract stage payments are due, under interim certificates, at monthly intervals on the 7th day of each calendar month (clause 30.1.3 and Appendix); the final date for payment is fourteen days after a certificate (clause 184.108.40.206); and the prescribed period for the purposes of section 111(2) is five days before the final date for payment (clause 24.2.1). It is therefore possible to state precisely how the contractual machinery should have operated, and to compare this with what actually happened (all dates referring to January 2006):
(a) an interim certificate should have been issued on the 7th (in fact the architect did not issue it until the 11th, and so it is necessary to work from that date);
(b) the final date for payment was therefore the 25th (but the certified amount was nevertheless due as from the 11th);
(c) the employer should have given its clause 24.2.1[b] (or section 110(2)) notice by the 16th (in fact it was a day late);
(d) the last date for a clause 220.127.116.11 (or section 111) notice was the 20th (the employer gave this notice on the 17th).
21. The clause 18.104.22.168 (or section 111) notice was effective when it was given, because the architect had not yet issued a certificate fixing a new completion date (which would, under clause 24.1, have cancelled the certificate of non-completion, which was a precondition to withholding part of a stage payment). The employer paid £126,359 on 20 January, and it was at that date the sum properly due from the employer. The extension of time granted by the architect on 23 January (not formally certified by him until some days later) could not retrospectively alter the fact that the employer had, on 20 January, paid the sum then properly payable by it. The obligation to make a further payment was dealt with separately by clause 24.2.2. Any other interpretation of the contract would ignore clause 24.2.2 and negate the underlying purpose of clause 24 as a whole (and also the purpose of Part II of the 1996 Act, which clause 24 gives effect to).
LORD BROWN OF EATON-UNDER-HEYWOOD
22. I have had the advantage of reading in draft the opinions of my noble and learned friends Lord Hope of Craighead, Lord Walker of Gestingthorpe and Lord Neuberger of Abbotsbury. I agree with them all and for the reasons they give I too would dismiss this appeal.
LORD NEUBERGER OF ABBOTSBURY
23. The issue on this appeal concerns the interrelationship of the provisions relating to damages for non-completion and those relating to extension of time contained in the JCT Standard Form of Building Contract 1998 Edition.
24. The contract the subject of the appeal was made on 16 January 2003 between Reinwood Ltd as employer, L Brown & Sons Ltd as contractor, and OMI Architects as architect. It was in the JCT Standard Form of Building Contract 1998 Edition, Private with Quantities, incorporating amendments 1 of 1999, 2 of 2000, and 3 of 2001. (The parties agreed certain amendments to this Form, but they are irrelevant for present purposes, and I shall therefore disregard them). The contract was for the construction of fifty-nine apartments on a site at Duke Street, Castlefield, Manchester. The Completion Date (as agreed by a subsequent amendment) was 18 October 2004, and liquidated and ascertained damages (known as LADs) were agreed at £13,000 per week or part thereof.
25. Clause 25 of the contract enabled the architect to give an extension of time on the application of the contractor by fixing such later date as the Completion Date as he then estimates to be fair and reasonable".
26. Clause 30 of the contract was concerned with Certificates and payments", and it included the following:
30.1 1.1 The Architect shall from time to time issue Interim Certificates stating the amount due to the Contractor from the Employer ; and the final date for payment pursuant to an Interim Certificate shall be 14 days from the date of issue of each Interim Certificate.
22.214.171.124 Not later than 5 days after the date of issue of an Interim Certificate, the Employer shall give written notice to the Contractor which shall, in respect of the amount stated as due in that Interim Certificate, specify the amount of the payment proposed to be made .
126.96.36.199 Not later then 5 days before the final date for payment of the amount due pursuant to clause to 188.8.131.52 the Employer may give a written notice to the Contractor which shall specify any amount proposed to be withheld and/or deducted from that due amount .
184.108.40.206 Where the Employer does not give any written notice pursuant to clause 220.127.116.11 and/or to clause 18.104.22.168.4 the Employer shall pay the Contractor the amount due pursuant to Clause 22.214.171.124. .
30.1.4 [I]f the Employer shall, subject to any notice issued pursuant to Clause 126.96.36.199, fail to pay the Contractor in full .by the final date for payment .and such failure shall continue for 7 days after the Contractor has given .written notice of his intention to suspend the performance of his obligations .then the Contractor may suspend such performance until payment in full occurs.....
27. Clause 24 of the contract was headed Damages for non-completion", and it was in these terms:
24.1 If the Contractor fails to complete the Works by the Completion Date then the Architect shall issue a certificate to that effect. [I omit a sentence inserted as an agreed amendment, but which rightly played no part in either partys argument]. In the event of a new Completion Date being fixed after the issue of such a certificate such fixing shall cancel that certificate and the Architect shall issue such further certificate under Clause 24.1 as may be necessary.
24.2.1 Provided: [a] the Architect has issued a certificates under Clause 24.1; and [b] the Employer has informed the Contractor in writing before the date of the Final Certificate that he may require payment of, or may withhold or deduct, [LADs], then the Employer may, not later then 5 days before the final date for payment of the debt due under the Final Certificate:
188.8.131.52 require in writing the Contractor to pay to the Employer [LADs] .for the period between the Completion Date and the date of Practical Completion .;
or 184.108.40.206 give a notice pursuant to Clause 220.127.116.11 .to the Contractor that he will deduct from monies due to the Contractor [LADs]. for the period between the Completion Date and the date of Practical Completion. 24.2.2 If, under Clause 25.3.3, the Architect fixes a later Completion Date ., the Employer shall pay or repay to the Contractor any amounts recovered, allowed or paid under Clause 24.2.1 for the period up to such later Completion Date.
24.2.3 Notwithstanding the issue of any further certificate of the Architect under Clause 24.1 any requirement of the Employer which has been previously stated in writing in accordance with Clause 24.2.1 shall remain effective unless withdrawn by the Employer.
28. Clause 28 of the contract was entitled Determination by Contractor". Clause 28.2.1 entitled the contractor to give the employer a notice of certain types of default which included a failure by the employer to pay by the final date of payment the amount properly due to the Contractor in respect of any certificate". Clause 28.2.4 provided, inter alia, that if the employer repeats a specified default", then the contractor may determine the employment of the contractor under the contract.
29. The two notices referred to in Clauses 24.2.1[b] and 18.104.22.168, and in Clauses 22.214.171.124 and 126.96.36.199, have their respective origins in sections 110 and 111, in Part II, of the Housing Grants, Construction and Regeneration Act 1996.